2000-046 - Laserfiche WebLink

Home Browse Search

4b +s PM Unit Price Work: 11.9 Where the Contract Documents provide that all or part of the Work is to he Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work times the estimated quantity of each items as indicated in the Agreement. The estimated quantities of items of Unit Price Work arc not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER in accordaM.ee with paragraph 9.l U 11.10 Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each separately identified item. 11.11 Where the quantity of any item of Unit Price Work performed by CON"IRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other items of Work and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as a result thereof, CONTRACTOR may make a claim for an increase in the Contract Price in accordance with Article 11 if the parties are unable to agree as to the amount of any such increase. ARTICLE 12 _ CHANGE OF CONTRACT TIM� 12.1 The Contract Time may only be changed by a change order or a written amendment. any claim for an extension or shortening of the contract time shall be based oat written notice delivered by tite party making claim to the other party and to ENGINEER promptly (but in no event later than thirty (30) days) after the occurrence of the event living rise to the claim and stating the general nature of the claim. Notice of the extent of the clairn with supporting data shall be delivered within sixty (60) days after such occurrence (unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall he accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by ENGINEER in accordance with paragraph 9.11. if OWNER and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid ifnot submitted in accordance with the requirements of this paragraph 12.1. 12.2 The Contract Time will be extended in an amount equal to time lost due to delays heyond the control of CONTRACTOR if a claim is made therefor as provided in paragraph 12.1. Such delays shall include, but not he limited to, acts or neglect by OWNER or others performing additional work as contemplated by Article 7, or to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. Delays described in this paragraph shall scot crnitle the CONTRACTOR to any additional compensation. The sole remedy of the CON FRAC'TOR shall be an extension of time obtained in accordance with Article 12. 12.3 All time limits stated in the Contract Documents are of the essence of the Agreement. ]'he provisions ofthis Article 12 shall not exclude recovery for damages (including but not limited to fees and charges of engineers, architects, attonicys and other professionals and court and arburation costs) for delay by either party. OF M z