2000-222 - Laserfiche WebLink

Home Browse Search

40 2.6.4 SUBMITTALS 2.6.4.1 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for lite limited purpose orchecking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with such reasonable promptness as to cause no delay in the Work or in the activities of the Owner, Contractor or separate contractors, while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not conducted for lite purpose of determining the accuracy and completeness of other details such as dimensions and quantities. or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the Contract Documents. The Architect's review shall not constitute approval of safely precautions or, unless otherwise specifically stated by (lie Architect, of any construction mralts, methods, teclwniqucs, sequences or procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which lite item is a component. 2,6.4.2 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance wvillw the requirements of tile, Contract Documents. 2.6.4.3 if professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of the Contractor by the Contract Documents, tile, Architect shall specify appropriate performance and design criteria that such services must satisfy, Shop Drawings and other submittals related to tits Work designed or certified by the design professional retained by the Contractor shall bear such professional's wvriltcn approval when submitted to the Architect. The Architect shall be entitled to rely upon Cite adequacy. accuracy and completeness of the services, cerlificnions or approvals performed by such design professionals. 2.6.5 CHANGE'S 1N THE WORK 2.6.5.9 The Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with [lie Contract Documents. The Architect may,tvilh the prior written Approval of lire vnefs Representative, authorize minor changes in the Work not involving an adjustment in Contract Sum or an extension of the Contract Time which are consistent with the intent of the Contract [Documents. If necessary. lite Architect shall prcporc. reproduce and distribute Drawings and Specifications to describe Work to be added. deleted or modified. as provided in Paragraph 2.11.2. 2.£.5.2 The Architect shall roview properly prepared, timely requests by lite owner or Contractor for changes in lite Work, including adjustments to the Contract Sum or Contract Time. A properly prepared request for a change in lite Work shall be accompanied by sufficient supporting data and information to permit the Architect to make a reasonable determination without extensive investigation or preparation of additional drawings or specifications, if the Architect determines that requested changes in lite Work are not materially different front lite requirements of the Contract Documents. the Architect stay With the prior written approval Atile, Owncr issue an order for a minor change in the Work or recommend to the Owner that the requested change be denied. 2.6,5.3 if (lie Architect determines that imphcmcntation of the requested changes would result in a material change to 1110 Contract that may cause an adjustment in lite Contract Time or Contract Sunt, lite Architect shall make a recommendation to the OWllcT. who may authorize further investigalioat of such change. Upon such authoriealion, and based upon information furnished by the Contractor, if any, the Architect shall estimate the additional cost :and time dual Wright restdt from such change. including any additional costs attribulable to a Change in Services of the Architect. With the Owner's wvritten_approval, the. Architect shall incorporate Chose estimates into a Change Order or oilier appropriate documcnlation for the Owners execution or negotiation with the Contractor. 2.6.6.4 The Architect shall maintain records relative to changes in the Work. 2,6.6 PROJECT COMPLETION 2.6.6.1 The Architect deal conduct inspections to determine the dale or dates of Substantial Completion and the date of final completion, shall receive from the Contractor and fogv�ard to the Owner. for the Owner's review and records. written warranties and related documents required by the Contract Documents and assembled by Cite Contntclor, and shall issue a final Certificate for Payment based upon a final inspection indicating; the Work complies with the requirements of the Contr.icl Documents. wLh UOf I!5l1?NI ilii-s'rAm3AR1) FORM SI:HL [CFS - 1997 EDITION - AIA - COPYRiou'r 1997 1 IW AMEHICAN INS a l ri rill M ARC llrl'F:C'TS, 1735 ,NI:W YAM AVN.NIT N -W, %vASIIIN(frON. D.C.21111116.5292. WARNIK[i I Miansod Phdu-901113lil-61 ,ll.ti Vv Y0P%1la— -d gill ubjmldieViotalo k pl pnx+.'utSiptt. TlriS &vrn yet VV a.+0mironiwlIV I)p Vr ids pammitn urdie At mrd � lw r piNmIuvxt tjW"All ViO14 In walil aye date t o nic Fo ui mutat 141-. Elcctrunici�omwat BILI -11)97