2024-094 - Laserfiche WebLink

Home Browse Search

Observations are to be limited to spot checking, selective measurement, and similar methods of general observation of the Work based on Consultant representative's exercise of professional judgment. Based on information obtained during such visits and such observations, Consultant's representative will evaluate whether Contractor's work is generally proceeding in accordance with the Contract Documents, and Consultant will keep Owner informed of the general progress of the Work. Consultant's inspector will prepare field reports of each site visit describing observations witnessed during site visits. Consultant will prepare field reports for the additional thirty (30) site visits performed through project completion. The purpose of Consultant representative's site visits will be to enable Consultant to better carry out the duties and responsibilities specifically assigned in this Agreement, and to provide the OWNER a greater degree of confidence that the completed Work will conform in general to the Contract Documents. Consultant shall not, during such visits or as a result of such observations of Contractor's work in progress, supervise, direct, or have control over Contractor's work, nor shall the Consultant have authority over or responsibility for the means, methods, techniques, equipment choice and usage, sequences, schedules, or procedures of construction selected by Contractor, for safety precautions and programs incident to Contractor's work, nor for any failure of Contractor to comply with laws and regulations applicable to Contractor's furnishing and performing the Work. Consultant will recommend to the Owner that Contractor's work be disapproved and rejected while it is in progress if, on the basis of such observations, Consultant believes that such work will not produce a completed Project that conforms generally to Contract Documents. TASK 2 — PROGRAMMING AND INTEGRATION — NO CHANGES TIME SCHEDULE Consultant's original proposal anticipated construction duration of twenty-four (24) months will be required. Amendment 1 assumed a revised final completion date of May 17, 2024. This Amendment 2 assumes a final completion date of August 2024. The updated construction duration is thirty-seven (37) months. FEESCHEDULE We will provide these services in accordance with our Agreement for Professional Services for Water Plant and Water Resources Engineering Services — RFQ 2019070, dated November 5, 2019, by and between INDIAN RIVER COUNTY, a political subdivision of the State of Florida ("COUNTY") and Kimley-Horn and Associates, Inc., ("Consultant"). The Consultant will provide professional services on a lump sum fee basis as follows: Task No. Task WO #6(Previously Authorized Amendment 1 Amendment 2 Revised Total Task I Construction Phase Services $865,774 $263,133 $51,359 $1,180,266 Task 2 Programming and Integration $356,772 $0 $0 $356,772 Total Lump Sum Fee $1,222,546 $263,133 $51,359 $1,537,038 K: (WPB CivillGenerallBlack0oridaVRCU10slo WTP Construction Phase (Amendment 2120240325 -Amendment 2 Oslo CPS.doc Page 2 oj6 Indian River County Utilities Department