2000-236 - Laserfiche WebLink

Home Browse Search

v s 401 not constitute a waiver of liquidated damages. G. jnspcetion and Accc ptan ,e of the Work The CONTRACTOR shall assist the COUNTY in performing all tests required to determine the acceptability of the work. The CONTRACTOR shall provide all samples and facilities and work necessary for the testings and inspection. "Select Fill" will be tested for compliance by an independent testing laboratory retained by the COUNTY. The CONTRACTOR must notify the COUNTY when Soil Replacement is taking place. Limits of excavation must be approved by the COUNTY prior to backfilling with "Select Fill". Upon notification by the CONTRACTOR, the ENGINEER will perform final tests and inspections. Should this reveal defective work those defects must be immediately corrected, after which additional tests and inspection shall be conducted by the ENGINEER to determine acceptability of the work. Upon acceptance of corrected defective work, this shall constitute final acceptance of the work. H. Lidos This project is a "Public Work" under Chapter 255, Florida Statutes. No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him. Such action shall not involve the OWNER in any expense. Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder "Notice; M71—mm + 04 IP . + M 1 1c K!VA in eversttb-ehcnntract hereunder." The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons, firms or corporations who are defined in Section 713.0 1, Florida Statutes, who have furnished labor or materials, employed directly or indirectly in the work, have been paid in full. ,Erotcction of Public Where there are telephone, telegraph, light, or power poles, water main, conduits, pipe, or drains; or other construction either public or private; in or on the streets or alleys; the work shall be so conducted that no interruption or delay will be caused in the operation or use of the some, Proper written notice shall be given and all the facilities afforded the owners of such construction encountered or likely to he encountered, as will enable them to preserve the same from injury. 2. The CONTRACTOR will not be permitted to interfere with public travel and convenience by grading or tearing up streets indiscriminately, but the work of conducting the various items of this Contract shall proceed in an orderly, systematic: and progressive maturer. Work under this contract will be paid on a lump sum or unit price basis as outlined on the Sid Form for the quantity of work installed. SUPPLEMENTARY CONDITIONS sc - 3