2000-301 - Laserfiche WebLink

Home Browse Search

6706-050 connection with this Contract, and his bonds will not be released by final . acceptance and payment by the OWNER unless all such c l aims are paid or released. ARTICLE 7. OTHER WORK SC-7 .5. Add a new paragraph immediately after paragrai,{h 7 .4 in the General Conditions which is to read as follows: 7.5. Should CONTRACTOR cause damage to th~ work or property of any separate contractor at the site, or should any c l aim arising out of CONTRACTOR's performance of the Work at the site be made by any separate contractor against CONTRACTOR, OWNER, ENGINEER, ENGINEER 's Consultants, the Construction Coordinator or any other person, CONTRACTOR shall promptly attempt to settl e with such other contractor by agreement, or to otherwise resolve the dispute by arbitration or at law. CONTRACTOR shall, to the fullest extent permitted by Laws and Regulations, Indemnify and hold OWNER, EMGINEER, ENGINEER'S Consultants and the Construction Coordinator harmless from and against all c laims, damages, losses and expenses (including, but not limited t?, fees of engineers, architects, attorneys and other professionals, and forms of dispute resolutions) arising directly, indirectly or consequentially out of any action, l egal or equitabl e, brought by any separate contractor against OWNER, ENGINEER, ENGINEER'S Consul tan ts or the Construction Coordinator to the extent based on :a claim arising out of CONTRACTOR's performance of the Work. Sho:.Jld a separate contractor cause damage to the Work or property of CONTRACTOR or should the performance of work by any separate contractor at the site give rise to any other claim, CONTRACTOR s hall not Institute a ny action, l egr.1I or equitable, against OWNER, l ENGINEER, ENGINEER 's Consultants or the Construction Coordinator or permit any action against any of them to be maintained and ·continued in Its name or for Its benefit In any court or before any arbiter which ::eeks to i mpose liability on or to recover damages from OWNER, ENGINEER, ENC?INEER's Consultants or the Construction Coordinator on account of any s ucl1 damage or claim. If CONTRACTOR is delayed at any time in performing or furnishing Work by any act or neglect of a separate contractor and OWNER and CONTRACTOR a re unable to agree as to the extent of any adjustment in Coni;ract Time s attributable thereto, CO NTRACTOR may make a c l aim for an extension of times in accordance with Article 12. An extension of the Contract Times shall be CONTRACTOR'S exclusive remedy with respect to OWNER, ENGINEER, ENGINEER's Consultants and Construction Coordinator for any delay. disruptio ll, intcrfercr>ce or hindrance caused by any separate contractor. This paragraph docs not prevent recovery from OWNER, ENGINEER, ENGINEER 's Consultant or Constructil,11 Coordinator for 00800 13 ' 211 110