Laserfiche WebLink
RESOLUTION . <br />Y 1 <br />WHEREAS, Indian River County, a political subdivision of the <br />State of. Florida, as Owner, and Netto Construction, Incorporated, <br />a Florida corporation, as Contractor, did on October 1, 1962, enter <br />into a building contract calling for the construction by.the Con, <br />tractor for the Owner of certain additions to the County Jail of <br />Indian River County, Florida; and, <br />WHEREAS, Nelson A. Faerber, the architect who prepared the plays <br />and specifications for said additions and who is supervising the con- <br />struction of same by the Contractor, has recommended that certain <br />changes be made to said plans and specifications; and, <br />WHEREAS, the Board of County Commissioners of Indian River County, <br />Florida, has found and does find that said changes in said plans and <br />specifications do not involve a substantial change in the general <br />plan or character of the construction to be done and, further,'that <br />delays, inconvenience and expenses incident to advertising for bids <br />would be numerous; and, <br />WHEREAS, said Board has been advised by its attorney that, under <br />the law of Florida as declared by the Supreme Court of Florida in <br />Escambia County v. Blount Construction Company, 1913, 62 So. 650, <br />it is not necessary to advertise for bids for such changes; NOW, <br />THEREFORE, <br />BE IT RESOLVED, by the Board of County Commissioners of Indian <br />River County, Florida, that Indian River County, a political sub- <br />division of the State of Florida, enter into a supplemental building <br />contract with Netto Construction, Incorporated, a Florida corpora- <br />tion, in words, phrases and figures as follows: <br />