2008-276 A - Laserfiche WebLink

Home Browse Search

12.03A and B Delete paragraphs 12.03.A and 12.03B of the General Conditions in their entirety and replace with the following: A. Where Contractor is delayed or prevented from completing any part of the Work within the Contract Times due to delay beyond the control of Contractor, the Contract Times (or Milestones) will be extended in an amount equal to the time lost due to such delay if (l) a Claim is made therefore as provided in paragraph 12.02.A and (2) Contractor provides evidence that the delay impacted the critical path of the Project. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect by Owner, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, abnormal weather conditions or acts of God. The Contractor must request the extension of time in writing and must provide the following information within the time periods stated hereafter. Failure to submit such information and in compliance with the time requirements hereinafter stated, shall constitute a waiver by the Contractor and a denial of the claim for extension of time: 1. Nature of the delay or change in the Work; 2. Dates of commencement and cessation of the delay or change in the Work; 3. Activities on the current progress schedule affected by the delay or change in the Work; 4. Identification and demonstration that the delay or change in Work affects the critical path; 5. Identification of the source of delay or change in the Work; 6. Anticipated extent of the delay or change in the Work; and 7. Recommended action to minimize the delay. B. Contractor hereby affirms that the extension of time granted herein is the Contractor's sole and exclusive remedy. Apart from extension of time, no payment or claim for damages shall be made to the Contractor as compensation for damages for any delays or hindrances from any cause whatsoever in the progress of the Work whether such delay is avoidable or unavoidable. SC 12.03C Delete paragraph 12.03.0 of the General Conditions in its entirety. SC 12.03D Delete paragraph 12.03D of the General Conditions in its entirety and replace with the following: In no event shall Owner, Engineer, or the Related Entities of either of them be liable to Contractor, any Subcontractor, any Supplier, any other person or organization, or any surety for or employee or agent of any of them, for any claim, cost, loss, or damages of any nature whatsoever arising out of or resulting from delays. ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK SC 13.04C. Delete paragraph 13.04.0 of the General Conditions in its entirety and replace with the following:. If it is found that the uncovered Work is defective, Contractor shall pay all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and Owner shall be entitled to an appropriate decrease in the Contract Price. SC 13.04D. Delete paragraph 13.04.D of the General Conditions in its entirety and replace with the 044572017 00800-13