2009-210 - Laserfiche WebLink

Home Browse Search

will take some or all of the following actions at no additional cost to the Owner, submitting to the Engineer for approval, a written statement of the steps he intends to take to remove or arrest the delay to the critical path in the approved schedule. 1. Increased construction manpower in such quantities and crafts as will substantially eliminate, in the judgment of the Engineer, the backlog of Work. 2. Increase the number of working hours per shift, shifts per working days per week, the amount of construction equipment, or any combination of the foregoing, sufficiently to substantially eliminate. in the judgment of the Engineer, the backlog of work. 3. Reschedule activities to achieve maximum practical concurrency of accomplishment of activities, and comply with the revised schedule. 4. Costs incurred by the Owner arising from such lengthening of hours, including furnishing of Inspectors, shall be the Contractor's responsibility and shall be deducted from monies due him. Failure of the Contractor to comply with the requirements of the Engineer may be grounds for determination by the Owner that the Contractor is not proceeding at such rates as will insure completion within the specified time and may result in the termination of the right of the Contractor to continue the Work. 3.02 ADJUSTMENT OF CONTRACT SCHEDULE AND COMPLETION TIME A. If the Contractor desires to make changes in his method of operating which affect the approved schedule, he shall notify the Engineer in writing stating what changes are proposed and the reason for the change. If the Engineer approves these changes, tha Contractor shall revise and submit for approval. without additional cost to the Owner, all of the affected portion of the schedule. The schedule shall be adjusted by the Contractor only after prior approval of his proposed changes by the Engineer. B. Adjustments may consist of changing portions of the activity sequence and/or activity durations, division of approved activities, or other adjustments as may be approved by the Engineer. The addition of extraneous, non -working activities and/or activities which add unapproved restraints to the schedule shall not be approved. C. If the completion of any activity, whether or not critical, falls more than 100 percent behind its approved duration, the Contractor shall submit for approval a schedule adjustment showing each such activity divided into two activities reflecting completed versus uncompleted work. D. Shop drawings which are not approved on the first submittal or within the scheduled time shall be immediately rescheduled.. as well as pipelines and tanks which do not pass leak tests. E. The contract completion time will be adjusted only for causes specified in this contract. In the event the Contractor requests an extension of any contract completion date, he shall furnish such justification and supporting evidence as the Engineer may deem necessary for determination as to whether the Contractor is entitled to an extension of time under the provisions of the contract. Engineer will, after receipt of such justification and supporting evidence make findings of fact and will advise the Contractor in writing thereof. If the Engineer finds that the Contractor is entitled to any extension of any contract completion date under the provisions of this contract, the Engineer's determination as to the total number of days of +1311-3 D \DIVISION 1101311 Construction Schedures.doc