2013-018B - Laserfiche WebLink

Home Browse Search

( B. Engineer will furnish a part-time Resident Project Representative. Contractor is responsible to give 24-hour notice on all required inspections so that the Resident Project Representative may be present. SC 9.04 A Delete the third sentence of paragraph 9.04A of the General Conditions in its entirety and replace with the following: However, if Contractor claims entitlement to additional time or money as a result of the Field Order, such entitlement is conditioned upon obtaining a Change Order authorized and executed by Owner after timely making a Claim as provided in the Contract Documents. SC 9.08-A: Delete the second sentence of 9.08A of the General Conditions in its entirety and replace with the following: Except for: (a) Claims for differing subsurface or physical conditions governed by paragraph 4.03; and (b) claims for time extensions governed by paragraph 12.03, all matters in question and other matters between Owner and Contractor arising prior to the date final payment is due, relating to the acceptability of the Work and the interpretation of the requirements of the contract documents pertaining to the performance of the Work, will be referred initially to Engineer in writing within 15 days after occurrence of the event giving rise to such Claim or within 15 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later; provided, however, the Owner shall make all final determination of such matters. SC 9.08-C Delete paragraph 9.08-C of the General Conditions in its entirety SC 9.08-D Delete paragraph 9.08-D of the General Conditions in its entirety ARTICLE 10 - CHANGES IN THE WORK; CLAIMS SC 10.03 A.3 Delete subparagraph 10.03.A.3 of the General Conditions in its entirety SC 10.05.A Delete paragraph 10.05.A of the General Conditions in its entirety and replace with the following: A. All Claims shall initially be referred to the Engineer for decision. SC 10.05.6 Delete paragraph 10.05.6 of the General Conditions in its entirety and replace with the following: Except for: (a) Claims for differing subsurface or physical conditions governed by paragraph 4.03; and (b) claims for time extensions governed by paragraph 12.03, Claims by either party shall be initiated within 15 days after occurrence of the event giving rise to such Claim or within 15 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later, by written notice of the amount or extent of the Claim, dispute, or other matter with supporting data to the Engineer and the other party by written notice stating the general nature of each Claim, dispute, or other matter delivered by the claimant to Engineer and the other party to the Contract. A Claim for an adjustment in Contract Price shall be prepared, in accordance with the provisions of paragraph 12.01.6. A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of paragraph 12.02.13. No claim by the Contractor for an equitable adjustment hereunder (� shall be allowed if asserted after final payment under this Contract. 00800-11