Laserfiche WebLink
6. Owner (two copies) <br />B. Instruct recipients to report promptly to the Contractor, in writing, any problems <br />anticipated by the projections shown in the schedule. <br />PART2-PRODUCTS <br />Not Applicable <br />PART 3 - EXECUTION <br />3.01 RESPONSIBILITY FOR SCHEDULE COMPLIANCE <br />A. The Contractor agrees that whenever it becomes apparent from the current monthly <br />schedule that delays to the critical path have resulted, and hence, that the contract <br />completion date will not be met or when so directed by the Owner, he will take some or <br />all of the following actions at no additional cost to the Owner, submitting to the Owner <br />for approval, a written statement of the steps he intends to take to remove or arrest the <br />delay to the critical path in the approved schedule. <br />1. Increased construction manpower in such quantities and crafts as will <br />substantially eliminate, in the judgment of the Owner's representative, the <br />backlog of Work. <br />2. Increase the number of working hours per shift, shifts per working days per <br />week, the amount of construction equipment, or any combination of the <br />foregoing, sufficiently to substantially eliminate, in the judgment of the Owner's <br />representative, the backlog of work. <br />3. Reschedule activities to achieve maximum practical concurrency of <br />accomplishment of activities, and comply with the revised schedule. <br />4. Costs incurred by the Owner arising from such lengthening of hours, including <br />furnishing of Inspectors, shall be the Contractor's responsibility and shall be <br />deducted from monies due him. Failure of the Contractor to comply with the <br />requirements of the Owner's representative may be grounds for determination by <br />the Owner that the Contractor is not proceeding at such rates as will insure <br />completion within the specified time and may result in. the termination of the <br />right of the Contractor to continue the Work. <br />3.02 ADJUSTMENT OF CONTRACT SCHEDULE AND COMPLETION TIlAE <br />A. If the Contractor desires to make changes in his method of operating which affect the <br />approved schedule, he shall notify the Owner in writing stating what changes are <br />proposed and the reason for the change. If the Owner approves these changes, the <br />Contractor shall revise and submit for approval, without additional cost to the Owner, all <br />of the affected portion of the schedule. The schedule shall be adjusted by the Contractor <br />only after prior approval of his proposed changes by the Owner. <br />B. Adjustments may consist of changing portions of the activity sequence and/or activity <br />durations, division of approved activities, or other adjustments as may be approved by the <br />Owner. The addition of extraneous, non -working activities and/or activities which add <br />unapproved restraints to the schedule shall not be approved. <br />044572017 <br />01311-3 <br />